Bill Text


Add To My Favorites | print page

SB-1352 Public works: prevailing wage rates: wage and penalty assessments.(2007-2008)

SHARE THIS: share this bill in Facebook share this bill in Twitter
SB1352:v92#DOCUMENT

Senate Bill No. 1352
CHAPTER 402

An act to amend Section 1742.1 of, and to amend and repeal Section 1742 of, the Labor Code, relating to public works.

[ Approved by Governor  September 27, 2008. Filed with Secretary of State  September 27, 2008. ]

LEGISLATIVE COUNSEL'S DIGEST


SB 1352, Wyland. Public works: prevailing wage rates: wage and penalty assessments.
Existing law requires the Labor Commissioner to issue a civil wage and penalty assessment to a contractor or subcontractor, or both, if the Labor Commissioner determines, after investigation, that the contractor or subcontractor, or both, violated the laws regulating public works contracts, including the payment of prevailing wages. Existing law permits the affected contractor or subcontractor to obtain review of a civil wage and penalty assessment or a notice of withholding, as defined, by transmitting a written request for a hearing to the office of the Labor Commissioner within 60 days after service of the assessment or notice and requires a hearing officer, as specified, or, after January 1, 2009, an administrative law judge appointed by the Director of Industrial Relations, to commence a hearing within 90 days of receipt of the request. Existing law provides that, after 60 days following the service of the assessment or notice, the affected contractor, subcontractor, and surety on a bond issued to secure the payment of wages, as provided, become liable for liquidated damages in an amount equal to the amount of unpaid wages, as specified. Existing law authorizes the hearing officer, as specified, or, after January 1, 2009, an administrative judge, to waive payment of the liquidated damages if the affected contractor or subcontractor demonstrates, as provided, that he or she had substantial grounds for believing the assessment or notice to be in error, and also permits the affected contractor or subcontractor to obtain review of the administrative decision by filing a petition for a writ of mandate to the superior court within 45 days after service of the decision.
This bill would continue to require a hearing officer, as specified, to hold the hearings, as provided, and would not require that an administrative law judge hold these hearings after January 1, 2009.
This bill would allow a contractor, subcontractor, or surety to deposit the full amount of the assessment for the Department of Industrial Relations to hold in escrow pending review, as specified, and to be distributed, as specified. If so deposited, there would be no liability for liquidated damages. This bill would authorize the Director of Industrial Relations to waive payment of liquidated damages, or a portion thereof, if the contractor or subcontractor demonstrates that there were substantial grounds for its appeal, as specified.
Vote: MAJORITY   Appropriation: NO   Fiscal Committee: NO   Local Program: NO  

The people of the State of California do enact as follows:


SECTION 1.

 Section 1742 of the Labor Code, as amended by Section 1 of Chapter 828 of the Statutes of 2006, is amended to read:

1742.
 (a) An affected contractor or subcontractor may obtain review of a civil wage and penalty assessment under this chapter by transmitting a written request to the office of the Labor Commissioner that appears on the assessment within 60 days after service of the assessment. If no hearing is requested within 60 days after service of the assessment, the assessment shall become final.
(b) Upon receipt of a timely request, a hearing shall be commenced within 90 days before the director, who shall appoint an impartial hearing officer possessing the qualifications of an administrative law judge pursuant to subdivision (b) of Section 11502 of the Government Code. The appointed hearing officer shall be an employee of the department, but shall not be an employee of the Division of Labor Standards Enforcement. The contractor or subcontractor shall be provided an opportunity to review evidence to be utilized by the Labor Commissioner at the hearing within 20 days of the receipt of the written request for a hearing. Any evidence obtained by the Labor Commissioner subsequent to the 20-day cutoff shall be promptly disclosed to the contractor or subcontractor.
The contractor or subcontractor shall have the burden of proving that the basis for the civil wage and penalty assessment is incorrect. The assessment shall be sufficiently detailed to provide fair notice to the contractor or subcontractor of the issues at the hearing.
Within 45 days of the conclusion of the hearing, the director shall issue a written decision affirming, modifying, or dismissing the assessment. The decision of the director shall consist of a notice of findings, findings, and an order. This decision shall be served on all parties and the awarding body pursuant to Section 1013 of the Code of Civil Procedure by first-class mail at the last known address of the party on file with the Labor Commissioner. Within 15 days of the issuance of the decision, the director may reconsider or modify the decision to correct an error, except that a clerical error may be corrected at any time.
The director shall adopt regulations setting forth procedures for hearings under this subdivision.
(c) An affected contractor or subcontractor may obtain review of the decision of the director by filing a petition for a writ of mandate to the appropriate superior court pursuant to Section 1094.5 of the Code of Civil Procedure within 45 days after service of the decision. If no petition for writ of mandate is filed within 45 days after service of the decision, the order shall become final. If it is claimed in a petition for writ of mandate that the findings are not supported by the evidence, abuse of discretion is established if the court determines that the findings are not supported by substantial evidence in the light of the whole record.
(d) A certified copy of a final order may be filed by the Labor Commissioner in the office of the clerk of the superior court in any county in which the affected contractor or subcontractor has property or has or had a place of business. The clerk, immediately upon the filing, shall enter judgment for the state against the person assessed in the amount shown on the certified order.
(e) A judgment entered pursuant to this section shall bear the same rate of interest and shall have the same effect as other judgments and shall be given the same preference allowed by law on other judgments rendered for claims for taxes. The clerk shall not charge for the service performed by him or her pursuant to this section.
(f) An awarding body that has withheld funds in response to a civil wage and penalty assessment under this chapter shall, upon receipt of a certified copy of a final order that is no longer subject to judicial review, promptly transmit the withheld funds, up to the amount of the certified order, to the Labor Commissioner.
(g) This section shall provide the exclusive method for review of a civil wage and penalty assessment by the Labor Commissioner under this chapter or the decision of an awarding body to withhold contract payments pursuant to Section 1771.5.

SEC. 2.

 Section 1742 of the Labor Code, as amended by Section 2 of Chapter 828 of the Statutes of 2006, is repealed.

SEC. 3.

 Section 1742.1 of the Labor Code is amended to read:

1742.1.
 (a) After 60 days following the service of a civil wage and penalty assessment under Section 1741 or a notice of withholding under subdivision (a) of Section 1771.6, the affected contractor, subcontractor, and surety on a bond or bonds issued to secure the payment of wages covered by the assessment or notice shall be liable for liquidated damages in an amount equal to the wages, or portion thereof, that still remain unpaid. If the assessment or notice subsequently is overturned or modified after administrative or judicial review, liquidated damages shall be payable only on the wages found to be due and unpaid.
Additionally, if the contractor or subcontractor demonstrates to the satisfaction of the director that he or she had substantial grounds for appealing the assessment or notice with respect to a portion of the unpaid wages covered by the assessment or notice, the director may exercise his or her discretion to waive payment of the liquidated damages with respect to that portion of the unpaid wages. Any liquidated damages shall be distributed to the employee along with the unpaid wages. Section 203.5 shall not apply to claims for prevailing wages under this chapter.
(b) Notwithstanding subdivision (a), there shall be no liability for liquidated damages if the full amount of the assessment or notice, including penalties, has been deposited with the Department of Industrial Relations, within 60 days following service of the assessment or notice, for the department to hold in escrow pending administrative and judicial review. The department shall release such funds, plus any interest earned, at the conclusion of all administrative and judicial review to the persons and entities who are found to be entitled to such funds.
(c) The Labor Commissioner shall, upon receipt of a request from the affected contractor or subcontractor within 30 days following the service of a civil wage and penalty assessment under Section 1741, afford the contractor or subcontractor the opportunity to meet with the Labor Commissioner or his or her designee to attempt to settle a dispute regarding the assessment without the need for formal proceedings. The awarding body shall, upon receipt of a request from the affected contractor or subcontractor within 30 days following the service of a notice of withholding under subdivision (a) of Section 1771.6, afford the contractor or subcontractor the opportunity to meet with the designee of the awarding body to attempt to settle a dispute regarding the notice without the need for formal proceedings. The settlement meeting may be held in person or by telephone and shall take place before the expiration of the 60-day period for seeking administrative review. No evidence of anything said or any admission made for the purpose of, in the course of, or pursuant to, the settlement meeting is admissible or subject to discovery in any administrative or civil proceeding. No writing prepared for the purpose of, in the course of, or pursuant to, the settlement meeting, other than a final settlement agreement, is admissible or subject to discovery in any administrative or civil proceeding. The assessment or notice shall advise the contractor or subcontractor of the opportunity to request a settlement meeting.
(d) This section shall become operative on January 1, 2007.